GENERAL SERVICES ADMINISTRATION ACQUISITION MANUAL (GSAM)
If the contracting officer determines under FAR 32.112-1 that a contractor’s certification of payment is inaccurate in any material respect, the contracting officer shall report the matter to the Office of Inspector General.
The contracting officer shall prepare the findings and determinations required by FAR 32.402(e) in coordination with the contract finance office. The HCA approves the findings, determinations and authorization for advance payments.
The contract finance office will give the contracting officer the interest rate to be charged on the unliquidated balance of advance payments.
The HCA must approve or disapprove requests for “unusual” progress payments.
Before providing for progress payments based on costs, the contracting officer shall request the Office of the Chief Financial Officer to provide advice and assistance about a contractor’s financial condition and the adequacy of its accounting system and controls.
The contracting officer shall ensure that the contract finance office provides to the contracting office:
(a) The date and amount of each progress payment to a contractor; and
(b) Written recommendations if findings warrant action by the Government.
The HCA must approve any action recommended under FAR 32.503-6. Upon approval, the contracting officer shall request the contract finance office to suspend or reduce payments.
Reduction of the liquidation rates specified in paragraph (b) of FAR 52.232-16 may be made only with the contracting officer’s approval after coordination with the contract finance office. Upon approval, the contracting officer shall request the finance office to reduce the rate.
(a) The contract finance office is responsible for the administration of debt collection pursuant to GSA directives, currently found in the Accounting Operations—Accounts Receivable and Credit and Finance Operations, and Related Activities Handbook (PFM P 4253.1).
(b) If the contracting officer determines that a debt in excess of $100 is delinquent, he/she shall notify the applicable finance office for collection in accordance with the Debt Collection Improvement Act of 1996, and possibly forward the information to the Department of the Treasury’s Financial Management Service for administrative offset and cross-servicing.
(c) If the contractor appeals the demand for payment pursuant to the Disputes clause of its contract, the contracting officer shall advise the Finance Office whether to suspend collection efforts pending resolution of the dispute.
GSA fiscal regulations are in the Budget Administration Handbook (CFO 4251.4), Accounting Classification Handbook (CFO P 4240.1), and Accounting Operations—Voucher Examination Payment Handbook (CFO P 4252.1).
GSA’s contract funding policies are in compliance with the full funding policy at Part 2, Section 31.6, OMB-C A-11, published June 26, 2008.
(a) “Severable services” means services that are continuing and ongoing in nature—such as help-desk support, maintenance, or janitorial services—for which benefit is received each time the service is rendered.
(b) “Non-severable services” means work that results in a final product or end-item and for which benefit is received only when the entire project is complete, such as systems design, building conversion, or environmental study.
(c) Contracts for severable services may cross fiscal years as long as the period of performance (excluding options) is no more than 12 months. Contracts for goods or non-severable services are not similarly limited.
(a) When acknowledging receipt of the notice of assignment, the contracting officer shall notify the contractor that all future invoices or other requests for payment under the contract must specify the name and address of the assignee and include a notation that payments due thereunder have been duly assigned. The contracting officer must send a copy of the acknowledgment to the contract finance office.
(b) When payments under requirements or indefinite quantity contracts that are for the sole use of GSA have been assigned, the contracting officer shall provide all GSA offices that will place orders against the contract the name and address of the assignee that will receive amounts due under the contract. The notification should also state that the contracting officer requested the contractor to specify the name and address of the assignee on future invoices.
532.806 Contract clauses.Insert the clause at 552.232-23, Assignment of Claims, in solicitations and requirements or indefinite quantity contracts under which more than one agency may place orders. |
Subpart 532.9—Prompt Payment
532.904 Determining payment due dates.Payment due dates for construction contracts are addressed at FAR 32.904(d). The following procedures apply to construction and building service contracts: (a) The amount of final payment must include, as appropriate, deductions to cover any of the following: (1) Liquidated damages for late completion. (2) Liquidated damages for labor violations. (3) Amounts withheld for improper payment of labor wages. (4) The amount of unilateral change orders covering defects and omissions. (5) The agreed-upon dollar amount in a Deficiency Report, which is included in all applicable Operation and Maintenance (O&M) service contracts. (b) When the contract is for the performance of building services, the contracting officer shall include the clause at 552.232-72, Final Payment Under Building Services Contracts. (c) When the contract is for the performance of building services, the contracting officer shall include the clause at 552.232-72, Final Payment Under Building Services Contracts. |
532.905 Payment documentation and process.For contracts of the type shown in 532.7201(a)(1) through (4): (a) Contractors are to submit invoices or vouchers to the contracting officer for approval. Invoices must be annotated with the date of receipt, as required by FAR 32.905. That date will be used to determine interest penalties for late payments. The contracting officer or designee must review the processing of invoices or vouchers before payment to determine if the items and amounts claimed are consistent with the contract terms and represent prudent business transactions. The contracting officer must ensure that these payments are commensurate with physical and technical progress under the contract. If the contractor has not deducted questionable amounts from the invoice or amounts required to be withheld, the contracting officer must make the required deduction, except as provided in 532.7203. Subject to 532.7201, the contracting officer must note approval of any payment on (or attached to) the invoice or voucher submitted by the contractor and forward the invoice or voucher to the appropriate contract finance office for retention after certification and scheduling for payment by a disbursing office. (b) See GSAM 532.7203 for the handling of audit findings. |
532.908 Contract clauses.(a) GSA has a FAR deviation that allows this agency to use the clause at 552.232-1, Payments, in lieu of the clause at FAR 52.232-1, Payments. (b) General. Before exercising the authority to modify the date for constructive acceptance or constructive approval of progress payments in paragraph (a)(5)(i) of the clause at FAR 52.232-25, Prompt Payment, the contracting officer must prepare a written justification explaining why a longer period is necessary. An official one level above the contracting officer must approve the justification. The time needed should be determined on a case-by-case basis, but the specified constructive acceptance period shall not exceed 30 days. (c) Stock, Special Order, and Schedules Programs. (1) GSA has obtained a FAR Deviation to authorize payment within 10 days of receipt of a proper invoice. The authority applies only to: (i) Orders placed by GSA under the referenced programs; (ii) That include FAR 52.232-33, Mandatory Information for Electronic Funds Transfer Payment; and (iii) For which the order is placed, and the contractor submits invoices, using EDI in accordance with the Trading Partner Agreement. |
(2) If the contract is for commercial items and will include FAR 52.212-4, use the clause with its Alternate II. If the contract is not for commercial items, use the clause at 552.232-25, Prompt Payment, instead of FAR 52.232-25. |
532.7003 Contract clause.For indefinite-delivery, indefinite-quantity (IDIQ) contracts other than Schedules, insert the clause at 552.232-77, Payment By Government Charge Card, if the contract will provide for payment by Government charge card as an alternative method of payment for orders. For Schedule contracts that provide for payment using the Government charge card, use the clause(s) prescribed at Part 538. |
(a) The contracting officer should not approve an initial invoice or voucher before having consulted with the Assistant Inspector General for Auditing or the Field Audit Office regarding cost or other supporting data as required under:
(1) Cost-reimbursement type contracts.
(2) The cost-reimbursement portion of fixed-price type contracts.
(3) Time and materials or labor-hour contracts.
(4) Fixed-price contracts providing for any of the following:
(i) Progress payments based on costs.
(ii) Advance payments.
(iii) Guaranteed loans.
(iv) Cost-based Incentives or redetermination.
(b) Except for fixed-price contracts with redetermination where no price revision (upward or downward) is to be made, the contracting officer shall not approve the final payment invoice or voucher for contracts specified in 532.7201(a) or the final payment or settlement of other contracts subject to audit prior to:
(1) Receipt and review of the contract audit report; or
(2) Consultation with the Assistant Inspector General for Auditing or the Field Audit Office if no audit is to be conducted.
(a) Contractors should be required to submit invoices or vouchers to the contracting officer. The date on which the contracting officer receives the invoice or voucher will be used to determine interest penalties for late payments. The contracting officer, or designee, must review the processing of invoices or vouchers before payment to determine if the items and amounts claimed are consistent with the contract terms and represent prudent business transactions. The contracting officer must ensure that these payments are commensurate with physical and technical progress under the contract. If the contractor has not deducted questionable amounts from the invoice or amounts required to be withheld, the contracting officer is responsible for making the required deduction, except as provided in 532.7203.
(b) Subject to 532.7201, the contracting officer should note approval of any payment on (or attached to) the invoice or voucher submitted by the contractor, then forward the invoice or voucher to the appropriate contract finance office for retention after certification and scheduling for payment by a disbursing office.
Audit reports will be furnished to the contracting officer and Field Audit Office, with a copy to the appropriate contract finance office. Upon receipt of an audit report, pursuant to contract terms, the contracting officer is responsible for determining the allowability of all costs covered by audit. While the auditor’s recommendations should be given full consideration, the contracting officer must make an independent business judgment before taking any action based on the audit report. If there is doubt or question about the auditor’s recommendations, the contracting officer is required to follow the audit resolution procedures in GSA Order ADM P 2030.2C, Audit Resolution and Followup System, Chapter 4, paragraph 3.
(a) The contracting officer shall notify the appropriate contract finance office in writing when amounts claimed for payment are—
(1) Suspended;
(2) Disapproved as not being allowable according to contract terms; or
(3) Not allocable to the contract.
(b) The contracting officer’s notice forms the basis for the contract finance office to issue GSA Form 533, Administrative Difference Statement. Finance will attach a copy of GSA Form 533 to each copy of the invoice or voucher from which the deduction has been made, and will include an explanation of the deduction.