FAC 2005-14
[Federal Register: November 22, 2006 (Volume 71, Number 225)]
48 CFR Chapter 1 and Parts 2, 4, et al.
Federal Acquisition Regulation; Interim and Final Rules
DEPARTMENT OF DEFENSE
GENERAL SERVICES ADMINISTRATION
NATIONAL AERONAUTICS AND SPACE ADMINISTRATION
48 CFR Chapter 1
Federal Acquisition Regulation; Federal Acquisition Circular 2005-14; Introduction
AGENCIES: Department of Defense (DoD), General Services Administration (GSA), and National Aeronautics and Space Administration (NASA).
ACTION: Summary presentation of final and interim rules, and technical amendments and corrections.
SUMMARY: This document summarizes the Federal Acquisition Regulation (FAR) rules agreed to by the Civilian Agency Acquisition Council and the Defense Acquisition Regulations Council in this Federal Acquisition Circular (FAC) 2005-14. A companion document, the Small Entity Compliance Guide (SECG), follows this FAC. The FAC, including the SECG, is available via the Internet at http://www.regulations.gov.
DATES: For effective dates and comment dates, see separate documents, which follow.
FOR FURTHER INFORMATION CONTACT: The analyst whose name appears in the table below in relation to each FAR case or subject area. Please cite FAC 2005-14 and specific FAR case number(s). For information pertaining to status or publication schedules, contact the FAR Secretariat at (202) 501-4755.
List of Rules in FAC 2005-14
Item |
Subject |
FAR case |
Analyst |
I |
Common Identification Standard for Contractors |
2005-015 |
Jackson |
II |
Removal of Sanctions Against Certain EU Countries. |
2005-045 |
Olson |
III |
Free Trade Agreements--Bahrain and Guatemala (Interim) |
2006-017 |
Parnell |
IV |
Free Trade Agreements--Morocco |
2006-001 |
Parnell |
V |
Technical Amendments |
SUPPLEMENTARY INFORMATION: Summaries for each FAR rule follow. For the actual revisions and/or amendments to these FAR cases, refer to the specific item number and subject set forth in the documents following these item summaries.
FAC 2005-14 amends the FAR as specified below:
Item I--Common Identification Standard for Contractors (FAR Case 2005-015)
This rule converts the interim rule published at 71 FR 208, January 3, 2006, to a final rule with changes. The rule amends the Federal Acquisition Regulation (FAR) by addressing the contractor personal identification requirements in Homeland Security Presidential Directive (HSPD) 12, ``Policy for a Common Identification Standard for Federal Employees and Contractors,'' and Federal Information Processing Standards Publication (FIPS PUB) Number 201, ``Personal Identity Verification (PIV) of Federal Employees and Contractors.'' The primary objectives of HSPD-12 are to establish a process to enhance security, increase Government efficiency, reduce identity fraud, and protect personal privacy by establishing a mandatory, Governmentwide standard for secure and reliable forms of identification issued by the Federal Government to its employees and contractors who require routine physical access to Federally-controlled facilities, and/or routine access to Federally-controlled information systems.
Item II--Removal of Sanctions Against Certain EU Countries (FAR Case 2005-045)
This rule converts the interim rule published at 71 FR 20305, April 19, 2006, to a final rule without change. The interim rule removed the sanctions in FAR Part 25 against Austria, Belgium, Denmark, Finland, France, Ireland, Italy, Luxembourg, the Netherlands, Sweden, and the United Kingdom on acquisitions not covered by the World Trade Organization Government Procurement Agreement. These sanctions did not apply to small business set-asides, to acquisition below the simplified acquisition threshold using simplified acquisition procedures, or to acquisitions by the Department of Defense. Contracting officers may now consider offers of end products, services, and construction that were previously prohibited by the sanctions.
Item III--Free Trade Agreements--Bahrain and Guatemala (FAR Case 2006-017) (Interim)
This interim rule allows contracting officers to purchase the goods and services of Guatemala and Bahrain without application of the Buy American Act if the acquisition is subject to the Free Trade Agreements. These trade agreements with Guatemala and Bahrain join the North American Free Trade Agreement (NAFTA), the Australia, Chile, Morocco, and Singapore Free Trade Agreements, and the CAFTA-DR with respect to El Salvador, Honduras, and Nicaragua, which are already in the FAR. The threshold for applicability of the Dominican Republic--Central America-United States Free Trade Agreement is $64,786 for supplies and services (the same as other Free Trade Agreements to date except Morocco and Canada) and $7,407,000 for construction (the same as all other Free Trade Agreements to date except NAFTA). The threshold for applicability of the Bahrain Free Trade Agreement is $193,000 (the same as the Morocco FTA and the WTO GPA) and $8,422,165 for construction (the same as NAFTA).
Item IV--Free Trade Agreements--Morocco (FAR Case 2006-001)
This final rule converts the interim rule published in the Federal Register at 71 FR 20306, April 19, 2006, to a final rule without change. This rule allows contracting officers to purchase the products of Morocco without application of the Buy American Act if the acquisition is subject to the Morocco Free Trade Agreements. The U.S. Trade Representative negotiated a Free Trade Agreement with Morocco, which went into effect January 1, 2006. This agreement joins the North American Free Trade Agreement (NAFTA) and the Australia, Chile, and Singapore Free Trade Agreements, which are already in the FAR. The threshold for applicability of the Morocco Free Trade Agreement is $193,000 for supplies and services and $7,407,000 for construction.
Item V--Technical Amendments
Editorial changes are made at FAR 15.404-1, 22.1006, 22.1304, 28.202, 52.212-5, 52.222-43, 52.228-15, and 52.228-16, in order to update references.
Dated: November 15, 2006.Ralph De Stefano, Director, Contract Policy Division.
Federal Acquisition Circular
Federal Acquisition Circular (FAC) 2005-14 is issued under the authority of the Secretary of Defense, the Administrator of General Services, and the Administrator for the National Aeronautics and Space Administration.
Unless otherwise specified, all Federal Acquisition Regulation (FAR) and other directive material contained in FAC 2005-14 is effective November 22, 2006.
Dated: November 12, 2006. Shay D. Assad, Director, Defense Procurement and Acquisition Policy.
Dated: November 8, 2006. Roger D. Waldron, Acting Senior Procurement Executive, General Services Administration.
Dated: November 6, 2006. Tom Luedtke, Assistant Administrator for Procurement, National Aeronautics and Space Administration.
[Federal Register: November 22, 2006 (Volume 71, Number 225)]
DEPARTMENT OF DEFENSE
GENERAL SERVICES ADMINISTRATION
NATIONAL AERONAUTICS AND SPACE ADMINISTRATION
48 CFR Parts 2, 4, 7, and 52
[FAC 2005-14; FAR Case 2005-015; Item I; Docket 2006-0020, Sequence 19]
Federal Acquisition Regulation;
FAR Case 2005-015, Common Identification Standard for Contractors
AGENCIES: Department of Defense (DoD), General Services Administration (GSA), and National Aeronautics and Space Administration (NASA).
ACTION: Final rule.
SUMMARY: The Civilian Agency Acquisition Council and the Defense Acquisition Regulations Council (Councils) have agreed to convert the interim rule published in the Federal Register at 71 FR 208 on January 3, 2006, to a final rule with changes. This final rule is amending the Federal Acquisition Regulation (FAR) to add the contractor personal identification requirements identified in the Homeland Security Presidential Directive (HSPD) 12, ``Policy for a Common Identification Standard for Federal Employees and Contractors,'' and Federal Information Processing Standards (FIPS) Number 201, ``Personal Identity Verification (PIV) of Federal Employees and Contractors,'' as amended.
DATES: Effective Date: November 22, 2006.
Applicability Date: This rule applies to solicitations and contracts issued or awarded on or after November 22, 2006. Contracts awarded before October 27, 2005 requiring contractors to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system must be modified to ensure that credentials are issued by October 27, 2007, pursuant to FAR Subpart 4.13 in accordance with agency implementation of FIPS PUB 201
and OMB guidance M-05-24, as amended.
FOR FURTHER INFORMATION CONTACT: For clarification of content, contact Mr. Michael Jackson, Procurement Analyst, at (202) 208-4949. Please cite FAC 2005-14, FAR case 2005-015. For information pertaining to status or publication schedules, contact the FAR Secretariat at (202) 501-4755.
SUPPLEMENTARY INFORMATION:
A. Background
This final rule amends the Federal Acquisition Regulation to require contracting officers to incorporate the requirement for contractors to comply with agency verification procedures that implement Homeland Security Presidential Directive-12 (HSPD-12), Office of Management and Budget (OMB) guidance M-05-24, and Federal Information Processing Standards Publication (FIPS PUB) Number 201 when applicable to the work to be performed under the contract.
DoD, GSA, and NASA published an interim rule in the Federal Register at 71 FR 208 on January 3, 2006. The 60-day comment period for the interim rule ended March 6, 2006. Five respondents provided comments. Most comments pointed out areas of concern and language that required clarification. The substantive comments are discussed below.
Public Comments
Comment: One respondent requested the Government clarify/elaborate on the requirements to have subcontractors properly cleared.
Response: Implementation of Homeland Security Presidential Directive (HSPD) 12 required by OMB memorandum M-05-24, Policy for a Common Identification Standard for Federal Employees and Contractors, follows the Federal Information Processing Standard Publication (FIPS PUB) 201 when individuals under contract with a Federal department or agency, requiring routine access to Federally-controlled facilities and/or Federally-controlled information systems, require identity credentials consistent with existing agency security policies. The need to have contactors meet the requirements of FIPS PUB 201, including background investigations, applies equally to contractors and subcontractors to the extent that subcontractors require routine access to Federally-controlled facilities and/or Federally-controlled information systems. As such, the Councils have revised the final rule to add the term ``routine'' to clarify that personal identity verification does not apply to all contractors and/or subcontractors.
Comment: One respondent stated there is an overlap with Department of Defense Instruction (DoDI) 3020.41 (October 3, 2005) paragraph 6.2.7.3 which states ``contingency contractor personnel shall be issued a standard Geneva Convention Card...U.S. citizens and selected other CDF will be issued a DoD Uniformed Services Identification and Privilege Card...'', and points out that FAC 2005-07 requires agencies to adopt and accredit a registration process consistent with the identity proofing, registrations and accreditation requirements in section 2.2 of FIPS [PUB] 201. The respondent asks will the requirement in DoDI 3020.41 satisfy the requirements of FAC 2005-07 for providing a personal identity card for contingency contractors? The respondent also asks does FAC 2005-07 duplicate or supplement the requirement in DoDI 3020.41 or does it depend on the contingency status of the contractor?
Response: Those contingency contractor personnel who receive a common access card (CAC), including those who receive a CAC based on the eligibility for a Geneva Conventions card, must comply with the identity proofing and vetting requirements of FIPS PUB 201, as the CAC represents DoD's implementation of the Personal Identity Verification (PIV) for Federal Employees and Contractors standard. Policy change is currently in staffing to modify and update existing documents to comply with the heightened requirements. The current DoDI 3020.41 does not satisfy FIPS PUB 201 requirements; pending publication of the policy changes, FIPS PUB 201 must be considered additive to the requirements of DoDI 3020.1.
Comment: One respondent highlights that the FIPS PUB 201 will be implemented in two phases, that the documents referenced in the interim rule are lengthy and a small business may not have the capability to download them, and that SBA may need to assist small businesses and/or provide training to make them competent in this arena. The respondent also stated that added administrative time is required for businesses and Federal agencies to incorporate the required contract modifications. The respondent also recommends that the standards required by parts 1 and 2 of the OMB memorandum (M-05-24) be outlined in the FAR clause at 52.204-9, and that the clause be added to solicitations and contracts in full text versus incorporation by reference.
Response: The rule permits modifications to be executed according to agency procedures for FIPS PUB 201 implementation. The Councils consider the October 2007 date to be in full compliance with FIPS PUB 201 and allow adequate time for agencies to establish a completion date to modify contracts thereby lessening any administrative burden. Agencies will establish their own procedures for complying with FIPS PUB 201, therefore the Councils do not want to give the appearance that the outline encompasses all facets of identity verification by including an outline in the clause. Because agency policy will implement FIPS PUB 201, agency resources should be available to assist small businesses with questions or concerns regarding their procedures. Adding the clause in solicitations and contracts by reference is the proper prescription, and the full text of clause 52.204-9 is available using the Internet. Nonetheless, a small business can receive clarification or a copy of the clause by contacting the contracting officer.
Comment: One respondent commented that the interim rule is a significant regulatory action and suggested that the budgetary and administrative impact is so significant it should be a ``major rule'' that is subject to congressional review pursuant to 5 U.S.C. 801 et seq. and to the regulatory planning and review process under Executive Order 12866.
Response: The budgetary and administrative resources to implement HSPD-12 are provided by the Government. The Councils have appropriately complied with the determination made by OMB's Office of Information and Regulatory Affairs that this rule is not significant, nor economically significant, nor a major rule.
Comment: One respondent commented that the HSPD-12 requires agencies to ``complete and receive notification of results of the FBI National Criminal History check prior to credential issuance.'' Both requirements will significantly increase the demands placed on Government investigative services far beyond their current budgetary and manpower capabilities. The respondent provided an overview of the backlog OPM is currently experiencing. The respondent indicates that hundreds of thousands more investigations will be required by HSPD-12 for government personnel, contractors, and subcontractors, and questions how the Government will handle the influx of contractor personnel. The respondent also stated the rule will cause an artificial increase in the number of investigations to ensure that personnel that may become critical to the contract performance are not excluded only because they do not have a government-issued I.D.
Response: Attachment A to the OMB Memo M-05-24 dated August 5, 2005, states that agencies should receive notification of results of the National Agency Checks before issuing a credential. However, the memo provides that the identity credential can be issued based on the FBI National Criminal History Check (fingerprint check) if the results are not received in 5 days. Because of this provision, the Councils have concluded that flexibilities exist to allow credentialing which may mitigate the impact of an increase in demand placed on investigative services. OPM is responsible for the investigative services and has procedures in place to handle the associated workload.
Comment: One respondent expressed that a concern for industry is the potential impact of this rule on the performance of contracts by contractors and subcontractors, because the rule is silent on the consequences of Government investigative services not being completed in a timely fashion. The respondent questions if an agency is allowed beyond October 27, 2005 to continue to provide access to ``federally-controlled facilities'' and/or ``federal information systems'' for contractors and subcontractors who are not yet adjudicated. Additional concern was expressed that a contractor or subcontractor would be barred from performing on a contract because the Government is unable to provide a final identity verification and successful criminal background check.
Response: In reference to the OMB Memo M-05-24, agencies are instructed to initiate National Agency Checks by October 27, 2005. Full completion will occur over a specified time period. The guidance includes instruction for distinguishing adjudicated individuals from those that have not yet been adjudicated; it does not prohibit access. Each agency will follow its own implementation policy for access authorization when a final identity verification and successful criminal background check are pending. Therefore, the Councils do not anticipate that contractors or subcontractors will be barred from performing their contractual obligations.
Comment: Two respondents question the course of action for contractors and subcontractors, including small and disadvantaged businesses, needing to obtain identity verification for their employees. It appears that the agency will be responsible for ensuring all contractor and subcontractor employees are able to complete the process, but such a sequence would indicate that verification occurs after award and employers who do not currently have adjudicated personnel would be required to delay performance on the contract until such time as a sufficient number of personnel can be adjudicated.
Response: As stated in the response above, implementation of HSPD-12 does not prohibit access to a Federally-controlled facility and/or Federally-controlled information system pending a final identity verification and successful criminal background check. Contractors must comply with agency procedures for access authorization when a final adjudication has not been issued. There is no intent to delay contract performance until a sufficient number of personnel can be adjudicated.
Comment: One respondent stated the prospect of investigative delays would drive businesses that can offer the Government successful commercial solutions from the marketplace because the delays would impact performance, and suggests a solution is to start verifying identity before contract award. However, this option would exacerbate the problem of workload delays that already plague the Government investigative services.
Response: The Councils have been informed by OPM that the full extent to which HSPD-12 will create investigative delays is unknown. It is anticipated that cases received by OPM because of HSPD-12 implementation, that would not otherwise have been received, will be almost exclusively for uncleared contractors. While the true size of this population is unknown, what is known is that a large number of agencies have been investigating uncleared contractors on a regular basis and the workload increase will be significantly smaller than if no activity had ever occurred. National Agency Check with Inquiries (NACI), the minimum investigation required for HSPD-12 compliance and personal identity verification (PIV) issuance, are not labor intensive. Once the case is data-entered, it is processed by automated systems. NACIs do not, other than in rare cases, require the use of field investigators. Further, PIV credentials can be issued upon favorable completion of the fingerprint portion of the NACI, which in most cases will be accomplished in a matter of days. The option of allowing contractors to begin the investigative process before contract award would create a far greater burden on the process. OPM is the authority on handling workload for investigative services, and has procedures to support implementation of HSPD-12.
Comment: One respondent stated it supports the need for secure and reliable forms of identification, but it is not clear that the Government has sufficiently anticipated the full scale of the impact on investigative services, historical delays, nor the potential impact on contractors and subcontractor and Government contracting as a whole on the Government's ability to verify the personnel for every contractor and subcontractor requiring access to ``federal information systems'' and/or ``federally-controlled facilities.''
Response: As stated in the above response, the Councils have been informed by OPM that the full extent to which HSPD-12 will create investigative delays is unknown, however, it is anticipated that cases received by OPM because of HSPD-12 implementation, that would not otherwise have been received, will almost exclusively be for uncleared contractors. OPM is responsible for handling investigative requests regarding HSPD-12 and has existing procedures to manage this type of workload.
Comment: One respondent stated the Councils must require as part of the rule that agencies submit information to the Government investigative services. Citing the November 9, 2005 testimony of Linda Springer, Director of the Office of Personnel Management, to the Senate Subcommittee on Oversight of Government Management, the Federal Workforce and the District of Columbia, this information will at least provide the bases for adequate, reasonable and accurate annual estimates of the personnel and costs demands they will place upon the process.
Response: In her November 9, 2005 testimony, Ms. Springer indicated that ``OPM will assist agencies in improving their workload forecasting by collecting quarterly data comparing agencies' annual workload projections with actual requests,'' and that OPM will continue to work toward reducing the time it takes to complete the process for investigative cases. The Councils support OPM's role in managing resources to perform investigations and OPM's procedures for gathering information for investigative services, and do not believe it is necessary to add further implementation requirements to this rule.
Comment: One respondent states the FAR interim rule sets a mechanism for requiring contractors to comply with HSPD-12 that differs from the OMB guidance. Because DOE has implemented the appropriate mechanism to assure contractors comply with HSPD-12, implementation of the FAR rule will cause hardship to the Department. The FAR policy requires agencies to follow HSPD-12 and its associated guidance. The policy states ``agencies must follow FIPS 201 and OMB guidance for personal identity verification for all affected contractor and subcontractor personnel...'' This policy language indicates that the FAR interim rule is intended to further the requirements of FIPS 201 and OMB guidance. This language clearly implies that for contractors which are not affected by HSPD-12, contracting officers do not have to include this clause.
Response: The Councils did not intend to overstate requirements to implement FIPS PUB 201 and the OMB guidance and agree that contracting officers do not have to include the clause if contract performance does not require compliance with HSPD-12. The final rule clarifies that HSPD-12 applies when contractors and subcontractors require routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system.
Comment: One respondent recommends that the FAR Interim Rule be modified for consistency with established HSPD-12 guidance, because the FAR requirement is not consistent with the recently amended FIPS PUB 201 and the OMB memorandum M-05-24. In particular, promulgation of the final rule as written could result in substantial confusion among the Federal agency employees and contractors who are assigned to implement HSPD-12 at large Federal agencies. The respondent listed items in the FAR interim rule which are different from the OMB memo including the definition of Federally-controlled facilities; the use of ``Federal Information System'' instead of ``Federally Controlled Information System''; the omission of ``facilities under a management and operation contract''; the exception for ``education institution''; and the expansion of the definition of ``Federally owned buildings and leased space'' to include property interests controlled by any department or agency.
Response: The Councils have reviewed updated FIPS PUB 201 guidance and have revised the definitions in the final rule for Federally-controlled facilities and Federally-controlled information systems to be consistent with the OMB Memo M-05-24, dated August 5, 2005.
This is not a significant regulatory action and, therefore, was not subject to review under Section 6(b) of Executive Order 12866, Regulatory Planning and Review, dated September 30, 1993. This rule is not a major rule under 5 U.S.C. 804.
B. Regulatory Flexibility Act The changes may have a significant economic impact on a substantial number of small entities within the meaning of the Regulatory Flexibility Act, 5 U.S.C. 601, et seq., because all entities that hold contracts or wish to hold contracts that require their personnel to have access to Federally-controlled facilities or information systems will be required to employ on Government contracts only employees who meet the standards for being credentialed and expend resources necessary to help employees fill out the forms for credentialing. The Councils prepared a Final Regulatory Flexibility Analysis (FRFA), and it is summarized as follows: 1. Statement of need for, and objectives of, the rule. This rule amends the Federal Acquisition Regulation to implement the Homeland Security Presidential Directive (HSPD) 12, ``Policy for a Common Identification Standard for Federal Employees and Contractors,'' dated August 27, 2004. HSPD 12 requires the development and agency implementation of a mandatory Governmentwide standard for secure and reliable forms of identification for Federal employees and contractors, including contractor employees.
2. Summary of significant issues raised by the public comments in response to the Initial Regulatory Flexibility Analysis (IRFA), a summary of the assessment of the agency of such issues, and a statement of any changes made in the interim rule as a result of such comments.
An interim rule was published in the Federal Register at 71 FR 208 on January 3, 2006. The Councils considered all of the comments in finalizing the rule. An Initial Regulatory Flexibility Analysis was performed. One respondent highlights that the FIPS PUB 201 will be implemented in two phases, that the documents referenced in the interim rule are lengthy and a small business may not have the capability to download them, and that SBA may need to assist small businesses and/or provide training to make them competent in this arena. The respondent also stated that added administrative time is required for businesses and Federal agencies to incorporate the required contract modifications. The councils consider the October 2007 date to be in full compliance with FIPS PUB 201 and allow adequate time for agencies to establish a completion date to modify contracts thereby lessening any administrative burden. Because agency policy will implement FIPS PUB 201, agency resources should be available to assist small businesses with questions or concerns regarding their procedures.
3. Description of, and an estimate of the number of, small entities to which the rule will apply or an explanation of why no such estimate is available.
This rule will apply to all large and small businesses that seek awards when contract performance requires contractors and/or subcontractors to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system. A precise estimate of the number of small entities that fall within the rule is not currently feasible because it would include both contractors who perform in Government-owned space as well as those who perform in Government-leased space (including employees of the lessor and its contractors).
The Councils did not receive any comments on this issue from small business concerns or other interested parties in response to the Initial Regulatory Flexibility Analysis.
4. Description of the projected reporting, recordkeeping, and other compliance requirements of the rule, including an estimate of the classes of small entities which will be subject to the requirement and the type of professional skills necessary for preparation of the report or record.
The rule does not directly require reporting, recordkeeping or other compliance requirements within the meaning of the Paperwork Reduction Act (PRA). The rule does require that any entity, including small businesses that will be performing a contract that requires its employees to have access to Federal facilities or information systems, submit information on their employees. Such information will include a personnel history for each employee having access to a Federal facility or information system for a period exceeding 6 months. Although the forms involved are similar to a standard application for employment that is used by many companies, it is envisioned that some employers, especially those using non-skilled or semi-skilled laborers, will need to help their employees complete the form. It is estimated that each applicant will spend approximately 30 minutes completing the form.
Five respondents provided public comments in response to the interim rule. The public expressed concern that downloading large documents may be problematic for small business concerns, there will be a significant increase workload for OPM resources who provide investigative services that may cause a delay and prohibit a contractor's ability to start performance while awaiting adjudication, and the interim rule overstated the credentialing requirements by referencing all contractors and subcontractors. The responses to public comments in the final rule preamble address these comments.
Agencies must adopt the technical standards for an approved identity proofing and registration process established by Federal Information Processing Standard Publication (FIPS PUB) 201, and establish their own implementation policy. The real implementation of this directive will occur at the agency level. Agencies should be prepared to assist contractors with questions or concerns about the agency policy.
5. Description of steps the agency has taken to minimize significant economic impact on small entities consistent with the stated objectives of applicable statutes, including a statement of the factual, policy, and legal reasons for selecting the alternative adopted in the final rule and why each of the other significant alternatives to the rule considered by the agency was rejected.
There are no known significant alternatives that will accomplish the objectives of the rule. No alternatives were proposed during the public comment period.
The FAR Secretariat has submitted a copy of the FRFA to the Chief Counsel for Advocacy of the Small Business Administration. Interested parties may obtain a copy from the FAR Secretariat. The Councils will consider comments from small entities concerning the affected FAR Parts 2, 4, 7, and 52 in accordance with 5 U.S.C. 610. Interested parties must submit such comments separately and should cite 5 U.S.C. 601, et seq. (FAC 2005-14, FAR Case 2005-015), in correspondence.
C. Paperwork Reduction Act The Paperwork Reduction Act does not apply because the changes to the FAR do not impose information collection requirements that require the approval of the Office of Management and Budget under 44 U.S.C. 3501, et seq.
List of Subjects in 48 CFR Parts 2, 4, 7, and 52
Government procurement. Dated: November 15, 2006. Ralph De Stefano, Director, Contract Policy Division.
Interim Rule Adopted as Final with Changes
Accordingly, DoD, GSA, and NASA adopt the interim rule amending 48 CFR parts 2, 4, 7, and 52, which was published in the Federal Register at 71 FR 208, January 3, 2006, as a final rule with the following changes:
1. The authority citation for 48 CFR parts 2, 4, 7, and 52 continues to read as follows:
Authority: 40 U.S.C. 121(c); 10 U.S.C. chapter 137; and 42 U.S.C. 2473(c).
PART 2--DEFINITIONS OF WORDS AND TERMS
2. Amend section 2.101 in paragraph (b)(2) by removing the definition ``Federal information system''; revising the definition ``Federally-controlled facilities''; and adding the definition ``Federally-controlled information system'' to read as follows:
2.101 Definitions.
* * * * *
(b) * * *
(2) * * *
Federally-controlled facilities means--
(1) Federally-owned buildings or leased space, whether for single or multi-tenant occupancy, and its grounds and approaches, all or any portion of which is under the jurisdiction, custody or control of a department or agency;
(2) Federally-controlled commercial space shared with non-government tenants. For example, if a department or agency leased the 10th floor of a commercial building, the Directive applies to the 10th floor only;
(3) Government-owned, contractor-operated facilities, including laboratories engaged in national defense research and production activities; and
(4) Facilities under a management and operating contract, such as for the operation, maintenance, or support of a Government-owned or Government-controlled research, development, special production, or testing establishment.
Federally-controlled information system means an information system (44 U.S.C. 3502(8) used or operated by a Federal agency, or a contractor or other organization on behalf of the agency (44 U.S.C. 3544(a)(1)(A)).
* * * * *
PART 4--ADMINISTRATIVE MATTERS
3. Revise section 4.1300 in paragraphs (a) and (b) and section 4.1301 to read as follows:
4.1300 Policy.
(a) Agencies must follow Federal Information Processing Standards Publication (FIPS PUB) Number 201, ``Personal Identity Verification of Federal Employees and Contractors,'' as amended, and the associated Office of Management and Budget (OMB) implementation guidance as amended, for personal identity verification for all affected contractor and subcontractor personnel when contract performance requires contractors to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system.
(b) Agencies must include their implementation of FIPS PUB 201 as amended, and OMB guidance M-05-24, dated August 5, 2005, as amended, in solicitations and contracts that require the contractor to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system.
* * * * *
4.1301 Contract clause.
The contracting officer shall insert the clause at 52.204-9, Personal Identity Verification of Contractor Personnel, in solicitations and contracts when contract performance requires contractors to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system. The clause shall not be used when contractors require only intermittent access to Federally-controlled facilities.
PART 7--ACQUISITION PLANNING
4. Amend section 7.105 by revising the last sentence in paragraph (b)(17) to read as follows:
7.105 Contents of written acquisition plans.
* * * * *
(b) * * *
(17) Security considerations. * * * For acquisitions requiring routine contractor physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system, discuss how agency requirements for personal identity verification of contractors will be met (see Subpart 4.13).
* * * * *
PART 52--SOLICITATION PROVISIONS AND CONTRACT CLAUSES
5. Amend section 52.204-9 by revising the date of the clause to read ``(NOV 2006)''; and revising paragraphs (a) and (b) to read as follows:
52.204-9 Personal Identity Verification of Contractor Personnel.
* * * * *
(a) The Contractor shall comply with agency personal identity verification procedures identified in the contract that implement Homeland Security Presidential Directive-12 (HSPD-12), Office of Management and Budget (OMB) guidance M-05-24, as amended, and Federal Information Processing Standards Publication (FIPS PUB) Number 201, as amended.
(b) The Contractor shall insert this clause in all subcontracts when the subcontractor is required to have routine physical access to a Federally-controlled facility and/or routine access to a Federally-controlled information system.
(End of clause)
[Federal Register: November 22, 2006 (Volume 71, Number 225)]
DEPARTMENT OF DEFENSE
GENERAL SERVICES ADMINISTRATION
NATIONAL AERONAUTICS AND SPACE ADMINISTRATION
48 CFR Parts 25 and 52
[FAC 2005-14; FAR Case 2005-045; Item II; Docket 2006-0020, Sequence 20]
Federal Acquisition Regulation; FAR Case 2005-045, Removal of Sanctions Against Certain EU Countries
AGENCIES: Department of Defense (DoD), General Services Administration (GSA), and National Aeronautics and Space Administration (NASA).
ACTION: Final rule.
SUMMARY: The Civilian Agency Acquisition Council and the Defense Acquisition Regulations Council (Councils) have agreed to adopt as final, without change, an interim rule that amended the Federal Acquisition Regulation (FAR) to remove the sanctions against certain European Union (EU) countries.
DATES: Effective Date: November 22, 2006.
FOR FURTHER INFORMATION CONTACT: For clarification of content, contact Mr. Jeremy Olson, at (202) 501-3221. Please cite FAC 2005-14, FAR case 2005-045. For information pertaining to status or publication schedules, contact the FAR Secretariat at (202) 501-4755.
SUPPLEMENTARY INFORMATION:
A. Background DoD, GSA, and NASA published an interim rule in the Federal Register at 71 FR 20305 on April 19, 2006. The interim rule deleted FAR Subpart 25.6, Trade Sanctions, and the clauses at FAR 52.225-15, Sanctioned European Union Country End Products, and FAR 52.225-16, Sanctioned European Union Country Services, and other associated references in FAR Part 25.
No comments were received by the close of the public comment period on June 19, 2006. Therefore, the Councils have agreed to convert the interim rule to a final rule without change.
This is not a significant regulatory action and, therefore, was not subject to review under Section 6(b) of Executive Order 12866, Regulatory Planning and Review, dated September 30, 1993. This rule is not a major rule under 5 U.S.C. 804.
B. Regulatory Flexibility Act The Department of Defense, the General Services Administration, and the National Aeronautics and Space Administration certify that this final rule will not have a significant economic impact on a substantial number of small entities within the meaning of the Regulatory Flexibility Act, 5 U.S.C. 601, et seq., because this rule only removes sanctions from--
End products from sanctioned EU countries with an estimated acquisition value less than $193,000;
Sanctioned EU country construction with an estimated acquisition value less than $7,407,000; or
Sanctioned EU country services with an estimated acquisition value less than $193,000 or that are excluded from coverage by the World Trade Organization Government Procurement Agreement.
These sanctions did not apply to small business set-asides, to acquisitions below the simplified acquisition threshold using simplified acquisition procedures, or to acquisitions by the Department of Defense.
C. Paperwork Reduction Act The Paperwork Reduction Act does not apply because the changes to the FAR do not impose information collection requirements that require the approval of the Office of Management and Budget under 44 U.S.C. 3501, et seq.
List of Subjects in 48 CFR Parts 25 and 52
Government procurement.
Dated: November 15, 2006.Ralph De Stefano,Director, Contract Policy Division.
Interim Rule Adopted as Final Without Change
Accordingly, the interim rule amending 48 CFR parts 25 and 52, which was published at 71 FR 20305, April 19, 2006, is adopted as a final rule without change.
[Federal Register: November 22, 2006 (Volume 71, Number 225)]
DEPARTMENT OF DEFENSE
GENERAL SERVICES ADMINISTRATION
NATIONAL AERONAUTICS AND SPACE ADMINISTRATION
48 CFR Parts 25 and 52
[FAC 2005-14; FAR Case 2006-017; Item III; Docket 2006-0020, Sequence 11]
Federal Acquisition Regulation; FAR Case 2006-017, Free Trade Agreements--Bahrain and Guatemala
AGENCIES: Department of Defense (DoD), General Services Administration (GSA), and National Aeronautics and Space Administration (NASA).
ACTION: Interim rule with request for comments.
SUMMARY: The Civilian Agency Acquisition Council and the Defense Acquisition Regulations Council (Councils) have agreed on an interim rule amending the Federal Acquisition Regulation (FAR) to implement the Dominican Republic--Central America--United States Free Trade Agreement with respect to Guatemala and the United States--Bahrain Free Trade Agreement.
DATES: Effective Date: November 22, 2006.
Comment Date: Interested parties should submit written comments to the FAR Secretariat on or before January 22, 2007.
ADDRESSES: Submit comments identified by FAC 2005-14, FAR case 2006-017, by any of the following methods:
Federal eRulemaking Portal: http://www.regulations.gov. Search for any document by first selecting the proper document types and selecting ``Federal Acquisition Regulation'' as the agency of choice. At the ``Keyword'' prompt, type in the FAR case number (for example, FAR Case 2006-001) and click on the ``Submit'' button. You may also search for any document by clicking on the ``Advanced search/document search'' tab at the top of the screen, selecting from the agency field ``Federal Acquisition Regulation'', and typing the FAR case number in the keyword field. Select the ``Submit'' button.
Fax: 202-501-4067.
Mail: General Services Administration, Regulatory Secretariat (VIR), 1800 F Street, NW, Room 4035, ATTN: Laurieann Duarte, Washington, DC 20405.
Instructions: Please submit comments only and cite FAC 2005-14, FAR case 2006-017, in all correspondence related to this case. All comments received will be posted without change to http://www.regulations.gov, including any personal and/or business confidential information provided.
FOR FURTHER INFORMATION CONTACT: For clarification of content, contact Ms. Jeritta Parnell, Procurement Analyst, at (202) 501-4082. Please cite FAC 2005-14, FAR case 2006-017. For information pertaining to status or publication schedules, contact the FAR Secretariat at (202) 501-4755.
SUPPLEMENTARY INFORMATION:
A. Background This rule amends FAR Part 25 and the corresponding clauses in Part 52 to implement the Dominican Republic--Central America--United States Free Trade Agreement (CAFTA-DR) with respect to Guatemala and the United States--Bahrain Free Trade Agreement (FTA). Congress approved these trade agreements in the Dominican Republic--Central America--United States Free Trade Agreement Implementation Act (Public Law 109-53) and the United States--Bahrain Free Trade Agreement Implementation Act (Pub. L. 109-169), respectively. These trade agreements waive the applicability of the Buy American Act for some foreign supplies and construction materials from Guatemala and Bahrain and specify procurement procedures designed to ensure fairness in the acquisition of supplies and services.
This interim rule adds Bahrain and Guatemala to the definition of ``Free Trade Agreement country.'' The rule also deletes Guatemala from the definition of ``Caribbean Basin country'' because, in accordance with Section 201(a)(3) of Pub. L. 109-53, when the CAFTA-DR agreement enters into force with respect to a country, that country is no longer designated as a beneficiary country for purposes of the Caribbean Basin Economic Recovery Act.
The excluded services for the Bahrain FTA are the same as for the CAFTA-DR, Chile FTA, and NAFTA. Guatemala has the same thresholds as the other CAFTA-DR countries. The Bahrain FTA threshold for supply and service contracts is $193,000. For construction contracts, the Bahrain FTA threshold is $8,422,165.
Like the Morocco FTA, the Bahrain FTA threshold for supplies and services is higher than the thresholds for the other FTAs. Therefore, Bahrainian end products are not covered by the Buy American Act--Free Trade Agreements--Israeli Trade Act provision and clause (FAR 52.225-3 and 52.225-4). Similarly, like NAFTA, the Bahrain FTA threshold for construction is higher than the thresholds of the other FTAs. Therefore Bahrainian construction material is excluded from coverage under the Buy American Act--Construction Materials under Trade Agreements provision and clause (52.225-11 and 52.225-12) for acquisitions less than $8,422,165 (Alternate I).
This is not a significant regulatory action and, therefore, was not subject to review under Section 6(b) of Executive Order 12866, Regulatory Planning and Review, dated September 30, 1993. This rule is not a major rule under 5 U.S.C. 804.
B. Regulatory Flexibility Act The interim rule is not expected to have a significant economic impact on a substantial number of small entities within the meaning of the Regulatory Flexibility Act, 5 U.S.C. 601, et seq. Although the rule opens up Government procurement to the goods and services of Guatemala and Bahrain, the Councils do not anticipate any significant economic impact on U.S. small businesses. The Department of Defense only applies the trade agreements to the non-defense items listed at DFARS 225.401-70, and acquisitions that are set aside for small businesses are exempt. Therefore, an Initial Regulatory Flexibility Analysis has not been performed. The Councils will consider comments from small entities concerning the affected FAR Parts 25 and 52 in accordance with 5 U.S.C. 610. Interested parties must submit such comments separately and should cite 5 U.S.C. 601, et seq. (FAC 2005-14, FAR case 2006-017), in correspondence.
C. Paperwork Reduction Act The Paperwork Reduction Act does apply, because the interim rule affects the certification and information collection requirements in the provisions at FAR 52.212-3, 52.225-4, 52.225-6, and 52.225-11 currently approved under OMB clearances 9000-0136, 9000-0130, 9000-0025, and 9000-0141 respectively. The impact, however, is negligible.
D. Determination to Issue an Interim Rule A determination has been made under the authority of the Secretary of Defense (DoD), the Administrator of General Services (GSA), and the Administrator of the National Aeronautics and Space Administration (NASA) that urgent and compelling reasons exist to promulgate this interim rule without prior opportunity for public comment. This action is necessary because the CAFTA-DR took effect with respect to Guatemala on July 1, 2006, and the Bahrain FTA took effect on August 1, 2006. However, pursuant to Public Law 98-577 and FAR 1.501, the Councils will consider public comments received in response to this interim rule in the formation of the final rule.
List of Subjects in 48 CFR Parts 25 and 52
Government procurement.
Dated: November 15, 2006. Ralph De Stefano, Director, Contract Policy Division.
Therefore, DoD, GSA, and NASA amend 48 CFR parts 25 and 52 as set forth below:
1. The authority citation for 48 CFR parts 25 and 52 continues to read as follows:
Authority: 40 U.S.C. 121(c); 10 U.S.C. chapter 137; and 42 U.S.C. 2473(c).
PART 25--FOREIGN ACQUISITION
25.003 [Amended]
2. Amend section 25.003 by--
a. Removing from the definition ``Caribbean Basin country'', ``Guatemala,'';
b. Adding to the definition in paragraph (2) of ``Designated country'', ``Bahrain,'' after ``Australia,'' and ``Guatemala,'' after ``El Salvador,'', and removing from paragraph (4), ``Guatemala,''; and
c. Adding to the definition ``Free Trade Agreement country'', ``Bahrain,'' after ``Australia,'' and ``Guatemala,'' after ``El Salvador,''.
3. Amend section 25.400 by removing from the end of paragraph (a)(2)(v) ``and''; adding at the end of paragraph (a)(2)(vi) ``and''; and adding a new paragraph (a)(2)(vii) to read as follows:
25.400 Scope of subpart.
(a) * * *
(2) * * *
(vii) United States-Bahrain Free Trade Agreement, as approved by Congress in the United States-Bahrain Free Trade Agreement Implementation Act (Pub. L. 109-169);
* * * * *
4. Amend section 25.401(b) by revising the third column of the table heading to read as follows:
25.401 Exceptions.
* * * * *
(b) * * *
* * * |
* * * |
Bahrain FTA, CAFTA-DR, Chile FTA, and NAFTA |
* * * |
* * * * *
25.402 [Amended]
5. Amend section 25.402(b), in the table, by adding after ``Australia FTA'' the entry ``Bahrain FTA'' and in its corresponding line items ``$193,000'', ``$193,000'', and ``$8,422,165'', respectively; and adding ``Guatemala,'' after ``El Salvador,''.
PART 52--SOLICITATION PROVISIONS AND CONTRACT CLAUSES
52.212-3 [Amended]
6. Amend section 52.212-3 by--
a. Revising the date of the clause to read ``(NOV 2006)'';
b. Adding in the second sentence of paragraph (g)(1)(i), ``Bahrainian end product,'' after ``The terms''; and
c. Removing from paragraph (g)(1)(ii), ``(other than Moroccan end products)'' and adding ``(other than Bahrainian or Moroccan end products)'' in its place, and removing from the table heading ``(Other than Moroccan End Products)'' and adding ``(Other than Bahrainian or Moroccan End Products)'' in its place.0
7. Amend section 52.212-5 by--
a. Revising the date of the clause;
b. Revising paragraph (b)(24)(i); and
c. Removing from paragraph (b)(25) ``(JUN 2006)'' and adding ``(NOV 2006)'' in its place.
The revised text reads as follows:
52.212-5 Contract Terms and Conditions Required to Implement Statutes or Executive Orders--Commercial Items.
* * * * *
CONTRACT TERMS AND CONDITIONS REQUIRED TO IMPLEMENT STATUTES OR
EXECUTIVE ORDERS--COMMERCIAL ITEMS (NOV 2006)
* * * * *
(b) * * *
(24)(i) 52.225-3, Buy American Act--Free Trade Agreements--Israeli Trade Act (NOV 2006) (41 U.S.C. 10a-10d, 19 U.S.C. 3301 note, 19 U.S.C. 2112 note, Pub. L 108-77, 108-78, 108-286, 109-53 and 109-169).
* * * * *
8. Amend section 52.225-3 by--
a. Revising the date of the clause;
b. Adding in paragraph (a), in alphabetical order, the definition ``Bahrainian end product'';
c. Adding in the definition ``Free Trade Agreement country'' ``Bahrain,'' after ``Australia,'' and ``Guatemala,'' after ``El Salvador,''; and
d. Removing from the first sentence of paragraph (c) ``(except the Morocco FTA)'' and adding ``(except the Bahrain and Morocco FTA)'' in its place; removing from the fourth sentence ``(other than a Moroccan end product)'' each time it appears (twice); and adding ``(other than a Bahrainian or Moroccan end product)'' in its place. The revised text reads as follows:
52.225-3 Buy American Act--Free Trade Agreements--Israeli Trade Act.
* * * * *
BUY AMERICAN ACT--FREE TRADE AGREEMENTS--ISRAELI TRADE ACT (NOV 2006)
(a) Definitions. * * *
Bahrainian end product means an article that--
(1) Is wholly the growth, product, or manufacture of Bahrain; or
(2) In the case of an article that consists in whole or in part of materials from another country, has been substantially transformed in Bahrain into a new and different article of commerce with a name, character, or use distinct from that of the article or articles from which it was transformed. The term refers to a product offered for purchase under a supply contract, but for purposes of calculating the value of the end product includes services (except transportation services) incidental to the article, provided that the value of those incidental services does not exceed that of the article itself.* * * * *
52.225-4 [Amended]
9. Amend section 52.225-4 by--
a. Revising the date of the clause to read ``(NOV 2006)'';
b. Adding to the second sentence in paragraph (a) ``Bahrainian end product,'' after ``The terms''; and
c. Removing from paragraph (b), ``(other than Moroccan end products)'' and adding ``(other than Bahrainian or Moroccan end products)'' in its place, and removing from the table heading ``(Other than Moroccan End Products)'' and adding ``(Other than Bahrainian or Moroccan End Products)'' in its place.
10. Amend section 52.225-5 by--
a. Revising the date of the clause;
b. Revising paragraph (2) of the definition ``Designated country''; and
c. Removing from paragraph (4) of the definition ``Designated country'', ``Guatemala,''.
The revised text reads as follows:
52.225-5 Trade Agreements.
* * * * *
TRADE AGREEMENTS (NOV 2006)
* * * * *
(a) * * *
Designated country * * *
(2) A Free Trade Agreement country (Australia, Bahrain, Canada, Chile, El Salvador, Guatemala, Honduras, Mexico, Morocco, Nicaragua, or Singapore);
* * * * *
11. Amend section 52.225-11 by--
a. Revising the date of the clause;
b. Revising paragraph (2) of the definition ``Designated country'';
c. Removing ``Guatemala'' from paragraph (4) of the definition ``Designated country''; and
d. Revising Alternate I.
The revised text reads as follows:
52.225-11 Buy American Act--Construction Materials under Trade Agreements.
* * * * *
BUY AMERICAN ACT--CONSTRUCTION MATERIALS UNDER TRADE AGREEMENTS
(NOV 2006)
* * * * *
(a) * * *
Designated country * * *
(2) A Free Trade Agreement country (Australia, Bahrain, Canada, Chile, El Salvador, Guatemala, Honduras, Mexico, Morocco, Nicaragua, or Singapore);
* * * * *
Alternate I (NOV 2006). As prescribed in 25.1102(c)(3), add the following definitions of ``Bahrainian construction material'' and ``Mexican construction material'' to paragraph (a) of the basic clause, and substitute the following paragraphs (b)(1) and (b)(2) for paragraphs (b)(1) and (b)(2) of the basic clause:
Bahrainian construction material means a construction material that--
(1) Is wholly the growth, product, or manufacture of Bahrain; or
(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in Bahrain into a new and different construction material distinct from the materials from which it was transformed.
Mexican construction material means a construction material that--
(1) Is wholly the growth, product, or manufacture of Mexico; or
(2) In the case of a construction material that consists in whole or in part of materials from another country, has been substantially transformed in Mexico into a new and different construction material distinct from the materials from which it was transformed.
(b) Construction materials. (1) This clause implements the Buy American Act (41 U.S.C. 10a - 10d) by providing a preference for domestic construction material. In addition, the Contracting Officer has determined that the WTO GPA and all the Free Trade Agreements except NAFTA apply to this acquisition. Therefore, the Buy American Act restrictions are waived for designated country construction materials other than Bahrainian or Mexican construction materials.
(2) The Contractor shall use only domestic or designated country construction material other than Bahrainian or Mexican construction material in performing this contract, except as provided in paragraphs (b)(3) and (b)(4) of this clause.
12. Amend section 52.225-12 in Alternate II, by revising the date of the alternate, the introductory text, paragraph (d)(1), and the first sentence of the introductory text of paragraph (d)(3) to read as follows:
52.225-12 Notice of Buy American Act Requirement--Construction Materials Under Trade Agreements.
* * * * *
Alternate II (NOV 2006). As prescribed in 25.1102(d)(3), add the definitions of ``Bahrainian construction material'' and ``Mexican construction material'' to paragraph (a) and substitute the following paragraph (d) for paragraph (d) of the basic provision:
(d) Alternate offers. (1) When an offer includes foreign construction material, except foreign construction material from a designated country other than Bahrain or Mexico, that is not listed by the Government in this solicitation in paragraph (b)(3) of FAR clause 52.225-11, the offeror also may submit an alternate offer based on use of equivalent domestic or designated country construction material other than Bahrainian or Mexican construction material.
* * * * *
(3) If the Government determines that a particular exception requested in accordance with paragraph (c) of FAR clause 52.225-11 does not apply, the Government will evaluate only those offers based on use of the equivalent domestic or designated country construction material other than Bahrainian or Mexican construction material. * * *
* * * * *
[Federal Register: November 22, 2006 (Volume 71, Number 225)]
DEPARTMENT OF DEFENSE
GENERAL SERVICES ADMINISTRATION
NATIONAL AERONAUTICS AND SPACE ADMINISTRATION
48 CFR Parts 25 and 52
[FAC 2005-14; FAR Case 2006-001; Item IV; Docket 2006-0020, Sequence 18]
Federal Acquisition Regulation; FAR Case 2006-001, Free Trade Agreements--Morocco
AGENCIES: Department of Defense (DoD), General Services Administration (GSA), and National Aeronautics and Space Administration (NASA).
ACTION: Final rule.
SUMMARY: The Civilian Agency Acquisition Council and the Defense Acquisition Regulations Council (Councils) agree to adopt as final, without change, an interim rule that amended the Federal Acquisition Regulation (FAR) to implement the new Free Trade Agreement with Morocco as approved by Congress (Public Law 108-302).
DATES: Effective Date: November 22, 2006.
FOR FURTHER INFORMATION CONTACT: For clarification of content, contact Ms. Jeritta Parnell, Procurement Analyst, at (202) 501-4082. Please cite FAC 2005-14, FAR case 2006-001. For information pertaining to status or publication schedules, contact the FAR Secretariat at (202) 501-4755.
SUPPLEMENTARY INFORMATION:
A. Background DoD, GSA, and NASA published an interim rule in the Federal Register at 71 FR 20306 on April 19, 2006, to implement the new Free Trade Agreement with Morocco as approved by Congress (Public Law 108-302). This Free Trade Agreement waives the applicability of the Buy American Act for some foreign supplies and construction materials from Morocco, and specifies procurement procedures designed to ensure fairness, applicable to the acquisition of supplies and services.
No comments were received by the close of the public comment period on June 19, 2006. Therefore, the Councils agreed to convert the interim rule to a final rule without change. This is not a significant regulatory action and, therefore, was not subject to review under Section 6(b) of Executive Order 12866, Regulatory Planning and Review, dated September 30, 1993. This rule is not a major rule under 5 U.S.C. 804.
B. Regulatory Flexibility Act The Department of Defense, the General Services Administration, and the National Aeronautics and Space Administration certify that this final rule will not have a significant economic impact on a substantial number of small entities within the meaning of the Regulatory Flexibility Act, 5 U.S.C. 601, et seq. Although the rule opens up Government procurement to the products of Morocco, the Councils do not anticipate any significant economic impact on U.S. small businesses. The Department of Defense only applies the trade agreements to the non-defense items listed at DFARS 225.401-70, and acquisitions that are set aside for small businesses are exempt.
C. Paperwork Reduction Act The Paperwork Reduction Act does apply; however, these changes to the FAR do not impose additional information collection requirements to the paperwork burden previously approved under OMB Control Numbers 9000-0025 and 9000-0141.
List of Subjects in 48 CFR Parts 25 and 52.
Government procurement.
Dated: November 15, 2006. Ralph De Stefano, Director, Contract Policy Division.
Interim Rule Adopted as Final Without Change
Accordingly, the interim rule amending 48 CFR parts 25 and 52, which was published at 71 FR 20306 on April 19, 2006, is adopted as a final rule without change.
[Federal Register: November 22, 2006 (Volume 71, Number 225)]
DEPARTMENT OF DEFENSE
GENERAL SERVICES ADMINISTRATION
NATIONAL AERONAUTICS AND SPACE ADMINISTRATION
48 CFR Parts 15, 22, 28, and 52
[FAC 2005-14; Item V; Docket FAR-2006-0021; Sequence 5]
Federal Acquisition Regulation; Technical Amendments
AGENCIES: Department of Defense (DoD), General Services Administration (GSA), and National Aeronautics and Space Administration (NASA).
ACTION: Final rule.
SUMMARY: This document makes amendments to the Federal Acquisition Regulation (FAR) in order to make editorial changes.
DATES: Effective Date: November 22, 2006
FOR FURTHER INFORMATION CONTACT: The FAR Secretariat, Room 4035, GS Building, Washington, DC, 20405, (202) 501-4755, for information pertaining to status or publication schedules. Please cite FAC 2005-14, Technical Amendments.
List of Subjects in 48 CFR Parts 15, 22, 28, and 52
Government procurement.
Dated: November 15, 2006. Ralph De Stefano, Director, Contract Policy Division.
Therefore, DoD, GSA, and NASA amend 48 CFR parts 15, 22, 28, and 52 as set forth below:
1. The authority citation for 48 CFR parts 15, 22, 28, and 52 continues to read as follows:
Authority: 40 U.S.C. 121(c); 10 U.S.C. chapter 137; and 42 U.S.C. 2473(c).
PART 15--CONTRACTING BY NEGOTIATION
2. Amend section 15.404-1(a)(7) by revising the last sentence to read as follows:
15.404-1 Proposal analysis techniques.
(a) * * *
(7) * * * They are available via the internet at http://www.acq.osd.mil/dpap/contractpricing/index.htm
* * * * *
PART 22--APPLICATION OF LABOR LAWS TO GOVERNMENT ACQUISITIONS
22.1006 [Amended]
3. Amend section 22.1006 in the fourth sentence of paragraph (c)(1) by removing ``(c)(1)'' and adding ``(d)(1)'' in its place.0
4. Amend section 22.1304 by revising paragraph (a) to read as follows:
22.1304 Procedures.
* * * * *
(a) Query the Department of Labor's VETS-100 Database via the Internet at http://www.vets100.com/Vets100Search.htm using the validation code ``vets'' to proceed with the search in the database; or
* * * * *
PART 28--BONDS AND INSURANCE
5. Amend section 28.202 by revising paragraph (d) to read as follows:
28.202 Acceptability of corporate sureties.
* * * * *
(d) The Department of the Treasury Circular 570 may be obtained from the U.S. Department of the Treasury, Financial Management Service, Surety Bond Branch, 3700 East West Highway, Room 6F01, Hyattsville, MD 20782. Or via the internet at http://www.fms.treas.gov/c570/.
PART 52--SOLICITATION PROVISIONS AND CONTRACT CLAUSES
52.212-5 [Amended]
6. Amend section 52.212-5 by revising the date of the clause to read ``(NOV 2006)''; removing from paragraph (b)(1) ``(JUL 1995)'' and adding ``(SEP 2006)'' in its place, and removing ``(SEP 2006)'' and adding ``(OCT 1995)'' in its place; and removing from paragraph (c)(3) ``(MAY 1989)'' and adding ``(NOV 2006)'' in its place.
52.222-43 [Amended]
7. Amend section 52.222-43 by revising the date of the clause to read ``(NOV 2006)''; and removing from paragraph (e) ``(c)'' and adding ``(d)'' in its place.
8. Amend section 52.228-15 by revising the date of the clause and paragraph (d) to read as follows:
52.228-15 Performance and Payment Bonds--Construction.
* * * * *
PERFORMANCE AND PAYMENT BONDS--CONSTRUCTION (NOV 2006)
* * * * *
(d) Surety or other security for bonds. The bonds shall be in the form of firmcommitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual sureties, or by other acceptable security such as postal money order, certified check, cashier's check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal Register or may be obtained from the U.S. Department of the Treasury, Financial Management Service, Surety Bond Branch, 3700 East West Highway, Room 6F01, Hyattsville, MD 20782. Or via the internet at http://www.fms.treas.gov/c570/.
* * * * *
9. Amend section 52.228-16 by revising the date of the clause and paragraph (e) to read as follows:
52.228-16 Performance and Payment Bonds--Other Than Construction.
* * * * *
PERFORMANCE AND PAYMENT BONDS--OTHER THAN CONSTRUCTION (NOV 2006)
* * * * *
(e) The bonds shall be in the form of firm commitment, supported by corporate sureties whose names appear on the list contained in Treasury Department Circular 570, individual sureties, or by other acceptable security such as postal money order, certified check, cashier's check, irrevocable letter of credit, or, in accordance with Treasury Department regulations, certain bonds or notes of the United States. Treasury Circular 570 is published in the Federal Register, or may be obtained from the U.S. Department of the Treasury, Financial Management Service, Surety Bond Branch, 3700 East West Highway, Room 6F01, Hyattsville, MD 20782. Or via the internet at http://www.fms.treas.gov/c570/
(End of clause)
* * * * *
END OF FAC 2005-14