PART 936 CONSTRUCTION AND ARCHITECT-ENGINEER CONTRACTS
Subpart 936.2 Special Aspects of Contracting for Construction. 936.202 Specifications.
Subpart 936.6 Architect-Engineer Services. 936.602-70 DOE selection criteria. 936.609-3 Work oversight in architect-engineer contracts.
Subpart 936.7 Standard and Optional Forms for Contracting for Construction, Architect-Engineer Services, and Dismantling, Demolition or Removal of Improvements 936.702 Forms for use in contracting architect-engineer services.
Subpart 936.71 Inspection and Acceptance 936.7100 Scope of subpart. 936.7101 Construction contracts.
Authority: 42 U.S.C. 7254; 40 U.S.C. 486(c). Source: 49 FR 12016, Mar. 28, 1984, unless otherwise noted.
__________________________________________
Subpart 936.2 Special Aspects of Contracting for Construction
936.202 Specifications.
(a) To support all invitations for bids, plans and specifications will be
available on request to all prospective bidders, including general contractors,
subcontractors, and material and equipment suppliers. Where the cost of
reproduction is $10 or more, the charge shall be a minimum of $10 and
subject to a maximum of $500, depending upon the size of the project
and the number of drawings and the volume of specifications involved.
Where the cost of reproduction is less than $10, the contracting officer
has authority to make distribution at cost of reproduction, or free of charge,
as a particular situation dictates.
(b) No refund for the return of plans and specifications will be made except
when the invitation is canceled. Under such circumstances, refund of payments
will be made upon return of the plans and specifications in good condition
to the issuing office.
(c) Plans and specifications will be issued without charge to such organizations
as The Associated General Contractors of America, American Road Builders'
Association, Dodge Reports, Blue Reports, Brown's Letters, Inc., builders
and contractors exchanges in the locality in which the project is to be constructed,
and others that maintain public plan display rooms.
(d) Payments received for plans and specifications shall be handled in accordance
with the regulations prescribed by the General Accounting Office in sections
3020-10 and 3030 of Title 7 of GAO Manual for Guidance of Federal Agencies.
(e) If the contracting officer desires to have the architect-engineer or construction
manager handle the furnishing of plans and specifications and payments therefor,
the invitations for bids should so state, and the architect-engineer or construction
management contract shall provide the manner in which the receipts are to be
handled, generally as a credit to the contract.
(f) No charge will be made to original receivers of plans and specifications for
revised sheets of drawings and revised pages of specifications which are issued
by amendments to invitations.
(g) Plans and specifications may be issued in complete sets only, or in complete
sets and parts of sets, as the Head of the Contracting Activity determines to be
best. If less than complete sets of plans and specifications are issued, the
distribution should be based on an applicant's request for specific pages and
drawing sheets.
(h) When a non-refundable fee is to be charged, a provision substantially
the same as 952.236-72 shall be included in the solicitation.
[60 FR 47308, Sept. 12, 1995]
Subpart 936.6 Architect-Engineer Services
936.602-70 DOE selection criteria.
Contracting officers or architect-engineer evaluation boards shall apply
the evaluation criteria contained in this subsection, as appropriate, and
any special criteria developed for individual selections. When special and
additional criteria are to be used, they shall be set forth in the public
announcement required by 936.601, and a written justification for their
use shall be placed in the DOE file maintained for the project.
(a) General qualifications, including:
(1) Reputation and standing of the firm and its principal members;
(2) Experience and technical competence of the firm in comparable work;
(3) Past record in performing work for DOE, other Government agencies,
and private industry, including projects or contracts implemented with
no overruns; performance from the standpoint of cost including cost
overruns (last 5 years); the nature, extent, and effectiveness of contractor's
cost reduction program; quality of work; and ability to meet schedules
including schedule overruns (last 5 years) (where applicable);
(4) The volume of past and present workloads;
(5) Interest of company management in the project and expected
participation and contribution of top officials;
(6) Adequacy of central or branch office facilities for the proposed
work, including facilities for any special services that may be required;
(7) Geographic location of the home office and familiarity with the
locality in which the project is located;
(8) In addition to these requirements, consider the Architect-Engineer
firm's experience in energy efficiency, pollution prevention, waste
reduction, and the use of recovered and environmentally preferable
materials and other criteria at FAR 36.602-1.
(Source: 68 FR 6358, Feb. 7, 2003)
(b) Personnel and organizations.
(1) Specific experience and qualifications of personnel proposed
for assignment to the project, including, as required for various
phases of the work:
(i) Technical skills and abilities in planning, organizing, executing,
and controlling;
(ii) Abilities in overall project coordination and management; and
(iii) Experience in working together as a team;
(2) Proposed project organization, delegations of responsibility,
and assignments of authority;
(3) Availability of additional competent, regular employees for support
of the project, and the depth and size of the organization so that any
necessary expansion or acceleration could be handled adequately;
(4) Experience and qualifications of proposed consultants and
subcontractors; and
(5) Ability to assign adequate qualified personnel from the
proposed organization (firms own organization, joint-venture
organizations, consulting firms, etc.) including key personnel
and a competent supervising representative.
(c) Additional (or special) criteria developed for the specific
project shall be considered and evaluated as may be appropriate.
936.609-3 Work oversight in architect-engineer contracts.
In addition to the clause at FAR 52.236-24, the contracting officer
shall insert the clause at 952.236-71 in architect-engineer contracts.
Subpart 936.7 Standard and Optional Forms for Contracting for
Construction, Architect-Engineer Services, and Dismantling,
Demolition, or Removal of Improvements
936.702 Forms for use in contracting for architect-engineer services.
(a) The contracting officer shall also include the additional terms at
952.236 - 70 in Standard Form 252 item 6.
Subpart 936.7100 Inspection and Acceptance
936.7100 Scope of subpart.
This subpart implements and supplements FAR Part 36 by
prescribing the policies and requirements for inspection
and acceptance under construction contracts.
936.7101 Construction contracts.
(a) Inspection services may be performed by the architect-engineer
repsonsible for the design. Inspection services may not be procured
from a construction contractor with respect to its own work.
(b) When one contractor is to inspect the work of another, the inspection
contractor will be given written instructions defining its responsibilities and
stating that it is not authorized to modify the terms and conditions of the
contract, to direct additional work, to waive any requirements of the contract,
or to settle any claim or dispute. Copies of the instructions will be given to the
contractor who is to be inspected, with a request to acknowledge receipt on a
copy to be returned to the contracting officer. In this manner, both contractors
are on express notice of the authority and limitations of the authority of the
inspecting contractor.
|