HHSAR 352.223-70 SAFETY AND HEALTH (JANUARY 2001)

(a)	To help ensure the protection of the life and health of all persons, and to help prevent damage to property, the Contractor shall comply with all Federal, State and local laws and regulations applicable to the work being performed under this contract. These laws are implemented and/or enforced by the Environmental Protection Agency, Occupational Safety and Health Administration and other agencies at the Federal, State and local levels (Federal, State and local regulatory/enforcement agencies).

(b)	Further, the Contractor shall take or cause to be taken additional safety measures as the Contracting Officer in conjunction with the project or other appropriate officer, determines to be reasonably necessary. If compliance with these additional safety measures results in an increase or decrease in the cost or time required for performance of any part of work under this contract, an equitable adjustment will be made in accordance with the applicable "Changes" Clause set forth in this contract.

(c)	The Contractor shall maintain an accurate record of, and promptly report to the Contracting Officer, all accidents or incidents resulting in the exposure of persons to toxic substances, hazardous materials or hazardous operations; the injury or death of any person; and/or damage to property incidental to work performed under the contract and all violations for which the Contractor has been cited by any Federal, State or local regulatory/enforcement agency. The report shall include a copy of the notice of violation and the findings of any inquiry or inspection, and an analysis addressing the impact these violations may have on the work remaining to be performed. The report shall also state the required action(s), if any, to be taken to correct any violation(s) noted by the Federal, State or local regulatory/enforcement agency and the time frame allowed by the agency to accomplish the necessary corrective action.

(d)	If the Contractor fails or refuses to comply promptly with the Federal, State or local regulatory/enforcement agency's directive(s) regarding any violation(s) and prescribed corrective action(s), the Contracting Officer may issue an order stopping all or part of the work until satisfactory corrective action (as approved by the Federal, State or local regulatory/enforcement agencies) has been taken and documented to the Contracting Officer. No part of the time lost due to any stop work order shall be subject to a claim for extension of time or costs or damages by the Contractor.

(e)	The Contractor shall insert the substance of this clause in each subcontract involving toxic substances, hazardous materials, or operations. Compliance with the provisions of this clause by subcontractors will be the responsibility of the Contractor.

(End of clause)