Part 42—Contract Administration and Audit Services

42.000 Scope of part.

42.001 [Reserved]

42.002 Interagency agreements.

42.003 Cognizant Federal agency.

Subpart 42.1—Contract Audit Services

42.101 Contract audit responsibilities.

42.102 Assignment of contract audit services.

42.103 Contract audit services directory.

Subpart 42.2—Contract Administration Services

42.201 Contract administration responsibilities.

42.202 Assignment of contract administration.

42.203 Contract administration services directory.

Subpart 42.3—Contract Administration Office Functions

42.301 General.

42.302 Contract administration functions.

Subpart 42.4—Correspondence and Visits

42.401 Contract correspondence.

42.402 Visits to contractors’ facilities.

42.403 Evaluation of contract administration offices.

Subpart 42.5—Postaward Orientation

42.500 Scope of subpart.

42.501 General.

42.502 Selecting contracts for postaward orientation.

42.503 Postaward conferences.

42.503-1 Postaward conference arrangements.

42.503-2 Postaward conference procedure.

42.503-3 Postaward conference report.

42.504 Postaward letters.

42.505 Postaward subcontractor conferences.

Subpart 42.6—Corporate Administrative Contracting Officer

42.601 General.

42.602 Assignment and location.

42.603 Responsibilities.

Subpart 42.7—Indirect Cost Rates

42.700 Scope of subpart.

42.701 Definition.

42.702 Purpose.

42.703 General.

42.703-1 Policy.

42.703-2 Certificate of indirect costs.

42.704 Billing rates.

42.705 Final indirect cost rates.

42.705-1 Contracting officer determination procedure.

42.705-2 Auditor determination procedure.

42.705-3 Educational institutions.

42.705-4 State and local governments.

42.705-5 Nonprofit organizations other than educational and state and local governments.

42.706 Distribution of documents.

42.707 Cost-sharing rates and limitations on indirect cost rates.

42.708 Quick-closeout procedure.

42.709-1 General.

42.709-2 Responsibilities.

42.709-3 Assessing the penalty.

42.709-4 Computing interest.

42.709-5 Waiver of the penalty.

42.709-6 Contract clause.

Subpart 42.8—Disallowance of Costs

42.800 Scope of subpart.

42.801 Notice of intent to disallow costs.

42.802 Contract clause.

42.803 Disallowing costs after incurrence.

Subpart 42.9—Bankruptcy

42.900 Scope of subpart.

42.901 General.

42.902 Procedures.

42.903 Solicitation provision and contract clause.

Subpart 42.10—[Reserved]

Subpart 42.11—Production Surveillance and Reporting

42.1101 General.

42.1102 Applicability.

42.1103 Policy.

42.1104 Surveillance requirements.

42.1105 Assignment of criticality designator.

42.1106 Reporting requirements.

42.1107 Contract clause.

Subpart 42.12—Novation and Change-of-Name Agreements

42.1200 Scope of subpart.

42.1201 [Reserved]

42.1202 Responsibility for executing agreements.

42.1203 Processing agreements.

42.1204 Applicability of novation agreements.

42.1205 Agreement to recognize contractor’s change of name.

Subpart 42.13—Suspension of Work, Stop-Work Orders, and Government Delay of Work

42.1301 General.

42.1302 Suspension of work.

42.1303 Stop-work orders.

42.1304 Government delay of work.

42.1305 Contract clauses.

Subpart 42.14—[Reserved]

Subpart 42.15—Contractor Performance Information

42.1500 Scope of subpart.

42.1501 General.

42.1502 Policy.

42.1503 Procedures.

Subpart 42.16—Small Business Contract Administration

42.1601 General.

Subpart 42.17—Forward Pricing Rate Agreements

42.1701 Procedures.